The Press-enterprise Published: 2/9, 2/16/24
NOTICE INVITING BIDS
The Jurupa Unified School District (“DISTRICT”) will receive sealed bids for the (“Project”) at the JUSD Purchasing Department, 4850 Pedley Road, Jurupa Valley, CA 92509 no later than , per the Purchasing Bid Clock at which time or thereafter said sealed bids will be opened and read aloud. Bids received after this time will be returned unopened. Bids shall be valid for sixty (60) days after the bid opening date.
This project will be bid and constructed using a Single General Contractor: Category 30 - Multiple Trades
The class(es) of California CONTRACTOR’S license(s) required in order to bid on and perform the contract for this Project is/are: Category 30 - Multiple Trades; License B
Licenses must be valid and active at the time of award of bid.
As a condition of submitting a bid for this Project, and in accordance with California Public Contract Code section 20111.5, prequalification of the prime CONTRACTOR is required. Only prime CONTRACTORS and MEP subcontractors who are prequalified and on the DISTRICT’S current annual prequalification list (as posted on the DISTRICT website) will be deemed to have met the requirements to bid on this Project. MEP subcontractors are those who perform work on the Project requiring one or more of the following licenses to perform the work designated: C-4, C-7, C-10, C-16, C-20, C-34, C-36, C-38, C-42, C-43 or C-46.
The DISTRICT will conduct pre-bid conference and site visits. Attendance is required at one of the following meetings;
SINGLE-PRIME:
CONTRACTOR’S
BID DOCUMENTS:
BID BOND:
BID FORMS:
BID PROCESS:
DVBE:
ALTERNATES: 23-24-06PD CAMINO REAL E.S. PH. 2
PREQUALIFICATION:
PREVAILING WAGES: 2:00 p.m. on Thursday, March 14, 2024
LICENSE:
PRE-BID CONFERENCE AND SITE VISIT: TWO (2) MANDATORY
MANDATORY Tuesday, February 20, 2024 at 10:00 a.m. or Thursday, February 22, 2024 at 10:00 a.m.
for the purpose of acquainting prospective Bidders with the bid documents and the work site. The pre-bid conferences will be at Camino Real Elementary School, 4655 Camino Real, Jurupa Valley, 92509. (Meet onsite in front of the administration office.)
The DISTRICT’S Project Planholder List will be generated exclusively from the roster of CONTRACTORS securing Bid Documents from the DISTRICT’S authorized reproduction firm, A & I Reprographics, or the CONSTRUCTION MANAGER via download. CONTRACTORS may, at their expense, obtain the documents necessary to submit a bid (“Bid Documents”) from A & I Reprographics at (909) 514-0704, or e-mail a request to bid@ aandirepro.com. Additionally, CONTRACTORS may secure the Bid Documents via free Procore download by e-mailing a request to Julie Wilson, juliew@neffcon.com . Bids must be submitted to the DISTRICT on the Contract Bid Forms, which are part of the bid package for the Project.
For information regarding this project, prospective Bidders are requested to contact Jordan Mierau, Neff Construction, Inc., jordan@ neffcon.com 1701 S. Bon View Avenue, Ontario, CA 91761, (909) 9473768.
All notices, clarifications, and addenda to this bid will be distributed by the above CM. The DISTRICT shall not be responsible for sending individual notification of changes or updates to any respondents. It is the sole responsibility of the Bidder to remain apprised of changes to this bid.
Each bid must be submitted with security in an amount not less than ten percent (10%) of the maximum bid amount as a guarantee that the Bidder will enter into the proposed contract, including all required Contract Documents. Such security must be in one of the following forms: (1) a cashier’s check or certified check made payable to the DISTRICT; or (2) a bond made payable to the DISTRICT in the form set forth in the Contract Documents. Any bond must have been issued by a California-admitted surety as defined in Code of Civil Procedure Section 995.120.
Bids must be submitted on DISTRICT bid forms. No other forms will be accepted.
The DISTRICT reserves the right to reject any or all bids or to waive any irregularities or informalities in any bids or in the bidding. Except as provided in Public Contract Code Section 5100 et sq. , no Bidder may withdraw a bid for a period of one hundred and twenty (120) calendar days after the opening of the bids.
The successful Bidder will be required to provide both a performance bond and a separate payment bond, each in an amount equal to 100% of the total contract amount. The forms of the bond are set forth in the Contract Documents and all bonds must be issued by a California-admitted surety as defined in California Code of Civil Procedure Section 995.120.
The successful Bidder and each of its subcontractor of any tier will be required to pay not less than the general prevailing rates of per-diem wages in the locality in which the work is to be performed for each craft or type of worker needed to execute the contract (“Prevailing Wages”). A copy of the perdiem rates of Prevailing Wages is available on the Department of Industrial Relations (“DIR”) website and a copy shall be posted at the Project site by Bidder. Pursuant to Labor Code sections 1725.5 and 1771.1, all CONTRACTORS and subcontractors that wish to bid on, be listed in a bid proposal, or enter into a contract to perform public work, must be registered with the DIR. No bid will be accepted nor any contract entered without proof of the CONTRACTORS and subcontractors current registration with the DIR to perform public work. If awarded a contract, the Bidder and its subcontractors, of any tier, shall maintain active registrations with the DIR for the duration of the Project. This Project is subject to compliance monitoring and enforcement by the DIR. In bidding on this Project, it shall be the Bidder ’s sole responsibility to evaluate and include the cost of complying with all labor compliance requirements under this contract and applicable law in its bid.
Where applicable, Bidders must meet the requirements set forth in Public Contract Code Section 10115 et seq., Military and Veterans Code Section 999 et seq. and California Code of Regulations, Title 2, Section 1896.60 et seq. regarding Disabled Veteran Business Enterprise (“DVBE”) Programs. Bidders may contact the DISTRICT for details regarding the DISTRICT’S DVBE participation goals and requirements.
PAYMENT AND PERFORMANCE BONDS:
If the DISTRICT requires that bids include additive or deductive alternates, the Bid Form will describe the specific alternates required. The award of the contract for the Project will be based on the lowest responsive base bid (Base Bid plus Allowance if applicable)
Date: February 2, 2024, By: Jeffrey Lewis, Director of Purchasing, Jurupa Unified School District, 4850 Pedley Road, Jurupa Valley, CA 92509
Advertised: February 2, 2024 and February 9, 2024 - Press-enterprise Pre-bid RFI Due Date: Thursday, March 7, 2024
The Press-enterprise Published: 2/2, 2/9/24
that a Public Hearing will be held by the Planning Commission of the City of Moreno Valley on the date and time set forth below:
NOTICE IS HEREBY GIVEN
CITY OF NORCO – NOTICE INVITING SEALED BIDS NORCO FIRST STREET STORM DRAIN PROJECT PUBLIC NOTICE IS HEREBY GIVEN that the City of NORCO, as AGENCY, invites sealed proposals for the above stated project and will receive such proposals on the City of Norco’s Bid and Vendor Portal, www.norco.ca.us/bid until February 29, 2024 at 12 p.m. The work to be done consists of furnishing all materials, equipment, tools, labor, and incidentals as required by the Plans, Specifications, and Contract Documents for the above stated project. The general items of work to be done hereunder consist of approximately 913 linear feet of 18” RCP storm drain pipe along with lateral pipes, manholes, and catch basins. The storm drain will be located within First Street, Valley View Avenue, and will connect to an existing drainage outlet. There are 60 working days allowed to complete this project. Please note that Notice to Proceed will be granted in accordance with Special Provision 6-1 with the understanding that Notice to Proceed will coincide with mobilization. Notice to Proceed will not be granted until the procurement schedule for major equipment has been established to the satisfaction of the City Engineer. Liquidated damages shall be assessed at $1,000 per working day. The City’s request for bids, bid results, and notices of an award are obtained through the City of Norco Vendor Portal, http://www.norco.ca.us/bid . All necessary forms, specifications and other bid documents may be viewed and downloaded electronically. Businesses who have registered in the Vendor Portal will receive email notices when a new request for bid or proposal relevant to their line of business is issued. Any interested party may view the City’s solicitations, as well as the bid results and final notices of award, by logging into the Vendor Portal and using the search features to locate the items of interest. The City’s policy is to award bids to the lowest responsive and responsible bidder. Requests for proposals are awarded to the company whose proposal provides the best overall value and best meets the needs of the City. The City reserves the right to reject any or all bids and to waive any irregularity or informality in any bid to the extent permitted by law. Specifications and Contract Documents are available in digital format (PDF) through the City of Norco's Vendor Portal on Planet Bids by clicking on the "Bids and RFPS" tab at the top of the City of Norco's website home page, then by clicking on the "BID AND RFP OPPORTUNITIES" icon. Contractor to strictly adhere to all State labor laws. Pursuant to Labor Code section 1771.1, all bidders are hereby notified that no contractor or subcontractor may be listed on a bid proposal for a public works project unless registered with the Department of Industrial Relations. Furthermore, all bidders are hereby notified that no contractor or subcontractor may be awarded a contract for public works on a public works project unless registered with the Department of Industrial Relations. Pursuant to the provisions of Section 1770-1777 of the Labor Code of the State of California, Director of the Department of Industrial Relations has ascertained the general prevailing rate of wages and employer payments for health and welfare, vacations, pension and similar purposes in the City in which the work is to be done. Information relative to the employment of apprentices shall be obtained from the Director of the Department of Industrial Relations, who is the Administrative Officer of the California Apprenticeship Council. The Contractor shall forfeit, as penalty to the Agency fifty dollars ($50.00) for laborers, workmen, or mechanics employed for each calendar day or portion thereof, if such laborer, workman or mechanic is paid less than the general prevailing rate of wages herein referred to and stipulated for any work done under the proposed contract, by him, or by any subcontractor under him, in violation of the provisions of the Labor Code and, in particular, Sections 1770 to 1781 inclusive. Copies of all collective bargaining agreements relating to the work as set forth in the aforementioned Labor Code are on file and available for inspection in the office of the Department of Industrial Relations, Division of Labor Statistics and Research. Affirmative action to ensure against discrimination in employment practices on the basis of race, color, national origin, ancestry, sex, or religion will be also required. Attention is directed to the provisions of Chapter 9, Division 3 of the Business and Professions Code requiring Contractors to be licensed. No proposal will be accepted from any Contractor unless they are licensed in accordance with the laws of this state. Contractor shall procure all permits incident to the lawful prosecution of the work. Further, the Labor Code of the State of California prohibits a Contractor from performing work on a public works project with a subcontractor who is ineligible pursuant to Section 1777.1 or 1777.7 of said code. The Contractor must possess a valid Contractor ’s License issued by the Contractor ’s State Board at the time the bid is submitted. The class of license shall be applicable to the work specified in the contract. The successful bidder shall be licensed according with the provisions of the Business and Professional Code and shall possess a Class A license at the time this contract is awarded. The successful Contractor and his/her subcontractors will be required to possess business licenses from the City of Norco. Construction shall be completed within sixty (60) working days after the Notice to Proceed is issued. The bid prices shall include all costs, including labor, materials, and all other incidental cost to complete the project, in compliance with the Bid and Contract Documents and applicable standards. All other work items not specifically listed in the bid schedule, but necessary to complete the work per bid and contract documents and applicable standards are assumed to be included in the bid prices. BIDDER understands that a bid is required for the entire work, that the quantities set forth in the Bid Schedule are to calculate total bid amount, and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. The Contract Documents call for monthly progress payments based upon the City’s estimate of the percentage of work completed. The AGENCY will retain 5 percent of each progress payment as security for completion of the balance of the work. At the request and expense of the successful Bidder, the City of Norco will pay the amounts so retained upon compliance with the requirements of Government Code Section 4590 and the provisions of the Contract Documents pertaining to Substitution of Securities. Bidders shall be responsible for verifying the issuance of addendums before submitting a bid. Each bidder shall fully acquaint himself/herself with the conditions relative to construction, labor, plan, specifications, and special provisions. Submission of the proposal shall be taken as conclusive evidence of this familiarity with the job site and conditions relative thereto. Bids/proposals must be prepared on the approved proposal forms in conformance with the Instructions to Bidders and submitted to the City of Norco’s Bid and Vendor Portal, www.norco.ca.us/bid . City of Norco, 2879 Clark Avenue, Norco, CA 92860 (951) 270-5607.
CITY OF MORENO VALLEY
PLANNING COMMISSION
NOTICE OF PUBLIC HEARING AND ENVIRONMENTAL DETERMINATION
To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of Wilma Jean Hawkins
has been filed by Sheri Dyson Clark in the Superior Court of California, County of Riverside
A PETITION FOR PROBATE
requests that Sheri Dyson Clark be appointed as authority to administer the estate under the independent administration of estates act.
THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.
THE PETITION FOR PROBATE
A hearing on the petition will be held in this court as follows:
Date: 02/22/2024
Time: 8:30 a.m. Dept.:12
Address of the Court: 4050 Main St., Riverside, CA 92501.
to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.
If you object
If you are a creditor or a contingent creditor of the decedent,
you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code.
Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.
You may examine the file kept by the court.
you may file with the court a (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code Section 1250. A
form is available from the court clerk. Attorney for Petitioner
Miles Clark III
3359 Chicago Ave.
Riverside, CA 92507
(951) 462-1800
If you are a person interested in the estate, Request for Special Notice
Special Notice
The Press-enterprise Published: 2/9, 2/16, 2/23/24
Request for
NOTICE OF PUBLIC SALE: Self-storage unit contents of the following customers containing household and other goods will be sold for cash by Base Self Storage at 1718 W Baseline St San Bernardino, CA 92411 to satisfy a lien on March 01, 2024 at approx: 12:00 pm at www. storagetreasures.com. Ernestine Medina, Elva Avila, Roque Medina, Kyra Sanchez, Kim Lee, Alberto Garcia, Manuel Uruiza, Adam Lee, Karon Diane Wagner, Jorge Santos, Paola Salazar, Jeremy Purkey.
The Sun (San Bernardino) Published: 2/9/24
FICTITIOUS BUSINESS NAME STATEMENT FILED
County of Riverside
Peter Aldana Assessor-county Clerk-recorder R-202400532 1/16/2024
The following person(s) is (are) doing business as:
Outback Pool Service & Repair 36268 Leeds Street, Winchester, CA. 92596
Full name of all registrants and address:
Scott Alan Moss
36268 Leeds Street Winchester, CA. 92596
This business is conducted by: Individual
Registrant
has not yet begun to business name(s) listed transact above.
I declare that all information in this statement is true and correct.
(A registrant who declares as true any material matter pursuant to Section 17913 of the Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000).)
/s/ Scott Alan Moss Owner/ Operator
This statement was filed with the County Clerk of Riverside County on date indicated by file stamp above
NOTICE - In Accordance with Subdivision (a) of Section 17920, a Fictitious Name Statement generally expires at the end of five years from the date on which it was filed in the office of the County Clerk, Except, as provided in Subdivision (b) of Section 17920, where it expires 40 days after any change in the facts set forth in the statement pursuant to Section 17913 other than a change in the residence address of a registered owner. A new Fictitious Business Name statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under federal, state, or common law (see Section 14411 et seq., Business Professions Code). I hereby certify that this copy is a correct copy of the original statement on file in my office.
Peter Aldana
Riverside County Clerk
The Press-enterprise
Published: 1/19, 1/26, 2/2, 2/9/24 FICTITIOUS BUSINESS NAME STATEMENT FILED
County of Riverside
Peter Aldana Assessor-county Clerk-recorder R-202401371 1/31/2024
The following person(s) is (are) doing business as:
SUTTLE FITNESS
33260 CAMINO RUBANO, TEMECULA, CA 92592 RIVERSIDE
Full name of all registrants and address:
Shawn Thomas Suttle 33260 Camino Rubano Temecula, CA 92592
State of Inc./org./reg.:
This business is conducted by: Individual
Registrant
California
has not yet begun to business name(s) listed transact above.
I declare that all information in this statement is true and correct.
(A registrant who declares as true any material matter pursuant to Section 17913 of the Business and Professions Code that the registrant knows to be false is guilty of a misdemeanor punishable by a fine not to exceed one thousand dollars ($1,000).)
/s/ Shawn Thomas Suttle Founder and President
This statement was filed with the County Clerk of Riverside County on date indicated by file stamp above
NOTICE - In Accordance with Subdivision (a) of Section 17920, a Fictitious Name Statement generally expires at the end of five years from the date on which it was filed in the office of the County Clerk, Except, as provided in Subdivision (b) of Section 17920, where it expires 40 days after any change in the facts set forth in the statement pursuant to Section 17913 other than a change in the residence address of a registered owner. A new Fictitious Business Name statement must be filed before the expiration. The filing of this statement does not of itself authorize the use in this state of a Fictitious Business Name in violation of the rights of another under federal, state, or common law (see Section 14411 et seq., Business Professions Code). I hereby certify that this copy is a correct copy of the original statement on file in my office.
Peter Aldana Riverside County Clerk The Press-enterprise Published: 2/9, 2/16, 2/23, 3/1/24